Serving Whitman County since 1877
Serving Whitman County since 1877
OWNER/LOCAL AGENCY: Town of Malden, Washington
PROJECT: Malden Well 3 Drilling and Testing
Contract No: PE21-96103-000
ENGINEER:
TD&H Engineering
303 E. 2nd Avenue, Spokane, WA 99202
(509) 622-2888
Estimated Cost of Project: $400,000 - $450,000
Sealed bids for the following described construction will be received by Town of Malden at:
(1) By mail to the office of the Clerk/Treasurer at P.O. Box 248, Malden, WA 99149, until 2:01:00 P.M., P.S.T., of the bid opening date. Notification by the Post Office will be considered as actual receipt of the bid by the Town of Malden.
(2) In the office of Clerk-Treasurer, Town Hall, Town of Malden at the Town Hall, W 204 Moreland, Malden, Washington, until 2:01:00 P.M, P.S.T., of the bid opening date. Bids delivered in person will be received only at the office of Clerk/Treasurer.
The bid opening date for this project shall be Thursday, September 13, 2022. The bids will be publicly opened and read after 2:01:00 P.M. on this date.
Bids must be completed on a lump sum and unit price basis as indicated on the BID PROPOSAL.
Availability of Bidding Documents:
Contract bid documents may be examined at the following locations:
1) Town of Malden, W 204 Moreland, Malden, WA 99149 (509) 569-3771
2) TD&H Engineering, 303 E. 2nd Avenue, Spokane, WA 99202 (509) 622-2888
3) Spokane Regional Plan Center 209 N. Havana Spokane, WA 99202 (509) 328-9600
4) Inland Northwest AGC, 4935 E. Trent Ave, Spokane, WA 99212 (509) 535-0391
5) Associated Builders & Contractors, 1760 E. Trent, Spokane, WA 99202 (509) 534-0826
6) Tri-City Construction Council, 20 East Kennewick Ave, Kennewick, WA 99336 (509) 582-7424
7) Builders Exchange of Washington, 2607 Wetmore Ave, Everett, WA 98201 (425) 258-1303
Contract documents are available at http://www.TDHplanroom.com and can be viewed and/or purchased online. All addenda will be issued through email. Bidders who order online are automatically placed on the Planholders’ List and will receive automatic e-mail notification of addenda. The Planholders’ List is available at this website. Contact TD&H Engineering if you wish to be added to the Planholders’ List.
Prospective bidders shall make all requests for clarifications to Marissa Siemens, PE, TD&H Engineering in writing at the above address or to marissa.siemens@tdhengineering.com. No verbal clarifications will be made.
Brief description of work:
The project consists of drilling and testing a new production well for the Town of Malden.
Bid security:
A certified or bank cashier’s check in the amount of five percent (5%) of the bid amount, payable to the Town of Malden, or bid bond executed by a licensed bonding company is required with each bid, subject to the conditions provided for in the bid procedures and conditions. No bidder may withdraw a bid within thirty (30) days after the actual date of the opening thereof.
Rejection of bids:
The Town shall have the right to reject any or all bids not accompanied by bid security or data required by the bidding document or a bid in any way incomplete or irregular.
All work performed on this project will be subject to state prevailing wage rates.
The Town of Malden is an Equal Opportunity and Affirmative Action Employer. Small, Minority- and Women-owned firms are encouraged to submit bids.
This project is funded through Washington State Public Works Board Program with state funds.
Contractors must be licensed to conduct business in Washington State.
Published: Aug. 25 and Sept. 1, 2022
Town of Albion
The first 2023 budget Public Hearing for revenues is set for September 13, 2022 @ 5:30 pm. The Public hearing will be held in the council chambers @ Town Hall 310 N F St. Albion WA.
Published: Aug. 25 and Sept. 1, 2022
NOTICE OF
DETERMINATION OF
NONSIGNIFICANCE (DNS)
Whitman County Planning issued a Determination of Nonsignificance (DNS) under the State Environmental Policy Act Rules (Chapter 197-11 WAC) for the following project:
A restoration project to clean out the channelized drainage of Frog Creek which flows into Union Flat Creek. To prevent localized flooding, sediment and excess plant growth shall be regularly removed to maintain the hydraulic capacity of the ditch and to reduce erosion. The soil removed from the site will be reclaimed back to the adjacent agricultural land.
The project is taking place in the SE ¼ of Section 14, Township 16 N., Range 42 E., and the NW ¼ of Section 23, Township 18 N., Range 42 E., W.M., Whitman County, Washington.
After review of a completed environmental checklist and other information on file with us, the Planning Office has determined that this proposal will not have a probable significant adverse impact on the environment.
Copies of the DNS are available at no charge from the Planning Office, Whitman County Public Service Building (2nd Floor), N. 310 Main St., Colfax, WA 99111.
Interested persons may submit environmentally-focused written comments on the SEPA decision by 5:00 PM on Thursday, August 25, 2022, to the County Planning Office, P.O. Box 430, Colfax, WA 99111-0430, (fax) 509-397-6210.
_________________________
Date: Thursday, August 25, 2022
Grace Di Biase
Assistant County Planner
SEPA 20-11
Published: Aug. 25, 2022
NOTICE
TOWN OF LACROSSE, WASHINGTON
REQUEST FOR
QUALIFICATIONS
TO PROVIDE
ARCHITECTURAL & ENGINEERING SERVICES
FOR PUBLIC WORKS SHOP CONSTRUCTION PROJECT
The Town of LaCrosse (Town) announces its intention to seek qualifications from qualified and experienced firms or individuals in providing Architectural and Engineering services to construct, repair, and update areas of a Public Works Shop. The entire RFQ can be requested from the Town Clerk/Treasurer at (509) 549-3330 or email lacrosse@pionnet.com.
SUBMISSION OF PROPOSAL
To receive consideration, proposals must be submitted in accordance with the following instructions:
1. All submitted proposals shall be sealed and delivered to:
Town of LaCrosse
Attn: Mayor
107 S. Main Street
PO Box 228
LaCrosse, WA 99143
Office hours are Monday through Thursday 8:30 am – 4:00 pm.
2. Submit three (3) copies of the response by 4:00 p.m. (PST) on September 8, 2022.
3. The envelope must be clearly marked “Proposal to Provide Architectural & Engineering Services for Public Works Shop”.
4. Modifications to submissions may be submitted prior to the date and time specified for receipt of submissions.
The Town reserves the right to reject any responses and can utilize its sole discretion to award a contract to the submittal it considers most favorable to the Town’s interests. The Town also has the right to waive minor irregularities in procedures.
August 16, 2022
Randy Camp, Mayor
Published: Aug. 18 and 25, 2022
ADVERTISEMENT FOR BIDS
Whitman County Public Works Solid Waste Transfer Station Scale Replacement
BID NO. XEW35
NOTICE IS HEREBY GIVEN that sealed Bids for the Whitman County Solid Waste Transfer Station Scale Replacement Project will be received in paper copy form by Whitman County Board of County Commissioners, State of Washington, at the Whitman County Public Works Building in Colfax, WA, until 10:45 am local time, on Monday, September 19, 2022, at which time all bids will be opened and publicly read. Any Bids received after the specified time will not be considered, regardless of the reason. Refer to the Bidder’s Checklist for a list of items that are required in the bid.
Each bid shall be separately sealed in an envelope and clearly marked with the name of the Bidder and the project name on the outside of the envelope. NO FACSIMILIES OR EMAILS WILL BE ACCEPTED. Handicap access to the Whitman County Public Works Building is available at the Mill Street Entrance.
Bidding Documents may be obtained at http://www.jubplanroom.com. Should you need assistance with this process, contact J-U-B ENGINEERS, Inc. at (509) 458-3727.
Bidders are strongly encouraged to attend the pre-bid meeting at 2:00 P.M. on Wednesday September 7, 2022 at the Solid Waste Transfer Station (252 Landfill Road, Pullman, WA 99163). For information concerning this project or to make a separate appointment to visit the project site, contact David Nails, Solid Waste & Recycling Director – (509) 334-2400. For other project related questions, contact Layne Merritt, P.E. at J-U-B ENGINEERS, Inc. – (509) 458-3727.
A more thorough note to bidders is included at the front end of the bidding documents, and serves as the complete Notice. The Owner reserves the right to reject any and all Bids, or any Bid not conforming to the intent and purpose of the Bidding Documents. No Bidder may withdraw their Bid within 60 days after the actual Bid Opening.
_________________________
Corey Mitzimberg,
Clerk of the Board
Published: Aug. 18 and 25, and Sept. 1, 2022
Public Notice
The Spokane Conservation District, Walt Edelen, 4422 E 8th Ave Spokane Valley, WA 99212-0292, is seeking coverage under the Washington State Department of Ecology’s Construction Stormwater NPDES and State Waste Discharge General Permit.
The proposed project, Little Hangman Creek Restoration Project, is located at 1051 S.R. 274, Tekoa, in Whitman County, Washington.
This project involves approximately 5.25 acres of soil disturbance for Stream Bank Stabilization/Habitat Restoration construction activities.
The receiving waterbody is Little Hangman Creek.
Any persons desiring to present their views to the Washington State Department of Ecology regarding this Application, or interested in Ecology’s action on this Application, may notify Ecology in writing no later than 30 days of the last date of publication of this notice. Ecology reviews public comments and considers whether discharges from this project would cause a measurable change in receiving water quality, and, if so, whether the project is necessary and in the overriding public interest according to Tier II anti-degradation requirements under WAC 173-201A-320.
Comments can be submitted to:
ecyrewqianoi@ecy.wa.gov, or
ATTN: Water Quality Program, Construction Stormwater
Washington State Department of Ecology
P.O. Box 47696
Olympia, WA 98504-7696
Published: Aug. 18 and 25, 2022
IN THE SUPERIOR COURT OF THE STATE OF
WASHINGTON
IN AND FOR THE COUNTY OF WHITMAN
------------------------------------------
SUMMONS BY PUBLICATION
No. 22-2-00155-38
)
)
)
JEFFREY S. PARKER and SHERRI J.PARKER, husband and wife, Plaintiffs,
v.
)
)
)
PATRICIA J. STANDRIDGE, also known of) record as PATI BRIGHAM, an unmarried ) person; and all other persons or parties unknown) claiming any right, title, estate, lien, or interest ) in the property herein described, Defendants.
--------------------------------
The State of Washington to the said Defendants, if living, and to their unknown heirs, if deceased; PATRICIA J. STANDRIDGE, also known of record as PATI BRIGHAM, an unmarried person, and all other persons or parties unknown claiming any right, title, estate, lien, or interest in the property herein described.
You are hereby summoned to appear within sixty (60) days after the date of first publication of this Summons, to-wit, within sixty (60) days after the 4th day of August, 2022, and defend the above-entitled action in the above-entitled court and answer the Complaint of the Plaintiffs and serve a copy of your Answer upon the undersigned attorneys for the Plaintiffs, at their office below stated; and in case of your failure to do so, judgment will be rendered against you according to the demands of the Complaint in this action which has been filed with the Clerk of said Court.
The object of this action is to quiet title in the Plaintiffs against the claims of all the Defendants and any one of them with respect to real estate in Whitman County, Washington, described as follows:
Lots 11, 12, 13, 14 and 15, Block 1, LaCrosse Original,
according to the plat thereof, recorded in Volume E of Plats,
page 24, records of Whitman County, Washington.
Parcel No. 1-0495-00-01-15-0000
DATED this 25th day of July, 2022.
MCGUIRE, DEWULF, KRAGT & JOHNSON, P.S.
By:MATTHEW D. JOHNSON
Attorney for Plaintiffs
WSBA No. 48045
105 S. Main St.
P.O. Box 619
Colfax, WA 99111-0619
Telephone: (509) 397-4345
Published: Aug. 4, 11, 18, and 25, and Sept. 1 and 8, 2022
PROBATE NOTICE
TO CREDITORS
(RCW 11.40.030) NO. 22-00099-38
IN THE SUPERIOR COURT OF THE STATE OF WASHINGTON IN AND FOR THE COUNTY OF WHITMAN IN THE
MATTER OF THE ESTATE OF JERRIE ANN JONES, Deceased.
The personal representative named below has been appointed as personal representative of this estate. Any person having a claim
against the decedent must, before the time the claim would be barred by any otherwise applicable statute of limitations, present the
claim in the manner as provided in RCW 11.40.070 by serving on or mailing to the personal representative or the personal
representative’s attorney at the address stated below a copy of the claim and filing the original of the claim with the court in which the probate proceedings were commenced. The claim must be presented within the later of: (1) Thirty days after the personal representative served or mailed the notice to the creditor as provided under RCW 11.40.020(1)(c); or (2) four months after the date of first publication of the notice. If the claim is not presented within this time frame, the claim is forever barred, except as otherwise provided in RCW 11.40.051 and 11.40.060. This bar is effective as to claims against both the decedent’s probate and nonprobate assets.
Date of First Publication: August 1, 2022
Personal Representative:
Jerry R. Jones
1200 SE SUNNYMEAD WAY
PULLMAN , WA 99163
206-940-8264
Attorney for the Personal Representative:
David Tracy
108 WELLS AVE. SOUTH
RENTON, WA 9
Published: Aug. 4, 11, 18, 25 and Sept. 1 and 8, 2022
PROBATE NOTICE TO CREDITORS
RCW 11.40.030
SUPERIOR COURT OF WASHINGTON, COUNTY OF WHITMAN
No. 22-4-00106-38
In the matter of the Estate of:
MARIE LYON, Deceased.
)
)
)
Jay Lyon has been appointed as Personal Representative of this Estate. Any person having a claim against the decedent must, before the time the claim would be barred by any otherwise applicable statute of limitations, present the claim in the manner as provided in RCW 11.40.070 by serving on or mailing to the Personal Representative or the Personal Representative’s attorneys at the address stated below, a copy of the claim and filing the original of the claim with the court in which the probate proceedings were commenced. The claim must be presented within the later of: (1) Thirty days after the Personal Representative served or mailed the notice to the creditor as provided under RCW 11.40.020(1)(c); or (2) four months after the date of first publication of the notice. If the claim is not presented within this time frame, the claim is forever barred, except as otherwise provided in RCW 11.40.051 and 11.40.060. This bar is effective as to claims against both the decedent’s probate and nonprobate assets.
Date of First Publication: August 11, 2022
Attorneys for the Personal Representative:
ESSER, SANDBERG & BOYD, PLLC
By Andrew C. Boyd, #42842
520 E Main St, Pullman, WA 99163
Published: Aug. 11, 18 and 25, 2022
PROBATE NOTICE TO
CREDITORS
RCW 11.40.030
SUPERIOR COURT OF WASHINGTON FOR WHITMAN COUNTY
No. 21-4-00105-38
In the matter of the Estate of:
AMY HEATHER BIORN, Deceased.
)
)
)
)
Sarah McGriff has been appointed as Personal Representative of this Estate. Any person having a claim against the decedent must, before the time the claim would be barred by any otherwise applicable statute of limitations, present the claim in the manner as provided in RCW 11.40.070 by serving on or mailing to the Personal Representative or the Personal Representative’s attorneys at the address stated below, a copy of the claim and filing the original of the claim with the court in which the probate proceedings were commenced. The claim must be presented within the later of: (1) Thirty days after the Personal Representative served or mailed the notice to the creditor as provided under RCW 11.40.020(1)(c); or (2) four months after the date of first publication of the notice. If the claim is not presented within this time frame, the claim is forever barred, except as otherwise provided in RCW 11.40.051 and 11.40.060. This bar is effective as to claims against both the decedent’s probate and nonprobate assets.
Date of First Publication: August 11, 2022
Attorneys for the Personal Representative:
ESSER, SANDBERG & BOYD, PLLC
By Andrew C. Boyd, WSBA #42842
520 E Main St, Pullman, WA 99163
Published: Aug. 18 and 25, and Sept. 1, 2022
REQUEST FOR STATEMENT OF QUALIFICATIONS (RSQ)
Town of Rosalia Request
for Qualifications Data to Furnish Engineering and Land Surveying Services
The Town of Rosalia (pursuant to Chapter 61, Laws of 1981) is inviting statements of
qualifications and performance information from firms interested in providing professional
engineering and land surveying services for existing and future town projects for 2022 through 2027. The projects for which engineering planning, design, and construction observation services and surveying services are sought may include wastewater treatment plant upgrades and collection system improvement projects, miscellaneous water system improvement projects, and transportation improvement projects.
These projects may be partially funded through the Washington State Community Development Block Grant Program with federal funds provided by the U.S. Department of Housing and Urban Development.
Qualification and performance statements will be reviewed, place on file for the 2022-2027 calendar years, and will be used as the source from which to select one or more qualified firms from whom a detailed proposal may be requested for any specific project.
Minority and women owned firms are encouraged to submit statements of qualifications.
The Town of Rosalia is an equal opportunity and affirmative action employer.
Firms desiring consideration shall submit a complete qualification package to the Town of Rosalia, Attn: Barb Leighton, Town Clerk, PO Box 277, Rosalia WA 99170 or hand delivered
to Town Hall, 110 W Fifth St., Rosalia. Qualification packages should be submitted by
1:30pm on September 6, 2022.
Published: Aug. 18 and 25, 2022
Reader Comments(0)